HomeMy WebLinkAbout2009-03-03-9:00AM-REGULAR
„!1 c = o ti 2 i 9
B12_AZOS COUNTY ~Y=V -
BRYAN, TEXAS
NOTICE OF MEETING
AND AGENDA
BRAZOS COUNTY COMMISSIONERS COURT
THE COMMISSIONERS COURT OF BRAZOS COLTIVTY WILL MEET IN REGULAR
SESSION ON 3 MARCH 2009 AT 9.00 A_M_ IN THE COMMISSIONERS COURTROOM OF THE COL7NTY ADMINISTRATION BUILDING, 200 SOUTH
TEXAS AVENUE, SUITE 106, BRYAN, TEXAS_
1 . invocation and Pledge of Allegiance Commissioner Mallard.
2. Call for citizen's input and/or concerns.
3_ Presentation by Paul F---spar with the City of Bryan on their capital improvement
proj ccts _
Consider and take action on agenda items 4 - 19-
4. Telecommunications Work Order with Texas ABr.M University for the installation of conduit and Fiber optic cabling to the Precinct 3 Justice of the Peace building-
5_ Budget Amendment 08/09 - 22.1 thrtl 224-
6- Request from the District Attorney's Office for permission to continue the Victim Assistance Coordinator position as part-time; this is a temporary change at no cost to
the County, to be re-evaluated again by 31 July 2009.
7_ Parsoi cl Change of Status.
8. Payment of Claims_
9. Cancellation of the regular session of Commissioners Court scheduled for 10 Marcb 2009; a quorum will not be available on tbat dat-
Offl of tha County Judge - 200 South Taxas Ave- Suite 332 Bryan, Texas 77803 Fax: (979) 36'1 503
ci
Commissioners Court Agenda
3 March 2009
Page 2
10. Contract with Patterson Architects for architectural and engineering services in the
remodeling of the Brazos County Courthouse.
11. Out of state travel request from the Expo Complex for Tom Quarles to attend the
International Managers' Conference and Trade Show in Boston, Massachusetts. Dates
of travel are 25-27 July 2009.
12. Tax Refund Applications for the following:
a. Hazel Todd (2) h. Fredriko's Mexican Bar & Grill
b. Mary Sue McRae i. Shoe Daze
c. LPS Property Tax Service j. Vision Insight
d. Citifinancial k. Angonia Printing
e. Brandon Berry Construction, Inc. 1. Pete's Comer
f. 7711 Employees Royalty in. Joe Tsung-Chow Su & Hui Fang Huang
g. Felix Fernandez-Ramos n. A. W. Jeanes, Jr.
13. Requisition 00023238 in the amount of $628,050.00 to Patterson Architects for
architectural and engineering services in the remodeling of the Brazos County
Courthouse.
14. Manual requisition in the amount of $18,105.00 to Texas A&M University for the
supply and installation of fiber optic cabling, conduit and the boring of necessary roads
for the Precinct 3 Justice of the Peace offices.
15. Permission to enter Charles Cotrone's property located off Cotrone-Dix Road for the
purpose of removing large trees for the health, safety and welfare of the general public.
Site is located in Precinct 4.
16. Permission to enter Tony Varisco's property located off Cotrone-Dix Road for the
purpose of creating a detour around a steep grade and railroad tracks, allowing County
equipment access to a work site for the health, safety and welfare of the general public.
Site is located in Precinct 4.
17. Permission to enter Lee Fazzino's property located of Cotrone-Dix Road for the
purpose of creating a detour around a steep grade and railroad tracks, allowing County
equipment access to a work site for the health, safety and welfare of the general public.
Site is located in Precinct 4.
18. Permission to enter Norman Ellison's property located off Jack Creek Road for the
purpose of replacing a 90` drop inlet for lake spillway under Jack Creek Road for the
health, safety and welfare of the general public. Site is located in Precinct 2.
19. Payment authorization in the amount of $27,500.00 to Patterson Architects for the
architectural pre-design services in the remodeling of the Brazos County courthouse.
20. Acknowledgement of the Monthly Reports submitted in February 2009. These reports
are available for review in the County Judge's Office.
Commissioners Court Agenda
3 March 2009
Page 3
21. Acknowledgement of the 2008 Racial Profiling Report for the Pct. 1 Constable's
Office.
22. Announcement of interest items and possible future agenda topics.
23. Call for citizen input and/or concerns.
24. Agency / Board / Committee reports by Court members.
25. Adjourn
PUBLIC COMMENTS
Public Comment during the Commission Meeting may be for all matters, both on and off the agenda, and be limited to
four minutes per person. Persons are invited to submit comments in writing on the agenda items and/or attend and make
comment at the Commission meeting. Members of the public are reminded that the Brazos County Commissioners
Court is a Constitutional Court, with both judicial and legislative powers, created under Article V, Section 1 and Section
18 of the Texas Constitution. As a Constitutional Court, the Brazos County Commissioners Court also possesses the
power to issue a Contempt of Court Citation under Section 81.024 of the Texas Local Government Code. Accordingly,
members of the public in attendance at any Regular, Special and/or Emergency meeting of the Court shall conduct
themselves with proper respect and decorum in speaking to, and/or addressing the Court; in participating in public
discussions before the Court; and in all actions in the presence of the Court. Those members of the public who are
inappropriately attired and/or who do not conduct themselves in an orderly and appropriate manner will be ordered to
leave the meeting. Refusal to abide by the Court's Order and/or continued disruption of the meeting may result in a
Contempt of Court Citation.
It is not the intention of the Brazos County Commissioners Court to provide a public forum for the demeaning of any
individual or group. Neither is it the intention of the Court to allow a member (or members) of the public to insult the
honesty and/or integrity of the Court, as a body, or any member or members of the Court, individually or collectively.
Accordingly, profane, insulting or threatening language directed toward the Court and/or any person in the Court's
presence and/or racial, ethnic or gender slurs or epithets will not be tolerated. Violation of these rules may result in the
following sanctions:
1. cancellation of a speaker's time;
2. removal from the Commissioners Court;
3. a Contempt Citation; and/or
4. such other and/or criminal sanctions as may be authorized
under the Constitution, Statutes and Codes of the State of Texas.
The County Commissioners Court can deliberate or take action only if a matter has been listed on an agenda properly
posted prior to the meeting. During the public comment period, speakers may address matters not listed on the published
agenda. The Open Meeting Law does not expressly prohibit responses to public comments by the Commissioners Court.
However, responses from the County Judge or Commissioners to unlisted public comment topics could become
deliberation on a matter without notice to the public. To ensure the public has notice of all matters the Commissioners
Court will consider, the County Judge and/or Commissioners may choose not to respond to public comments, except to
correct factual inaccuracies, recite existing policy in response to an inquiry or to ask that a matter be listed on a future
agenda. See Texas Open Meetings Act §551.042.
The County Administration Building is wheelchair accessible. Handicap parking spaces are available. Any request for sign
interpretive services must be made two working days before the meeting. To make arrangements, please call (979) 361-4102.
COMMISSIONERS' COURT
REGULAR MEETING
MARCH 3, 2009
A regular meeting of the Commissioners' Court of Brazos
County, Texas was held in the Brazos County Commissioners
Courtroom in the Administration Building, 200 South Texas
Avenue, in Bryan, Brazos County, Texas, beginning at 9:00 a.m.
on Tuesday, March 3, 2009 with the following members of the
Court present:
Randy Sims, County Judge, Presiding;
Lloyd Wassermann, Commissioner of Precinct l;
Duane Peters, Commissioner of Precinct 2;
Kenny Mallard, Commissioner of Precinct 3;
Carey Cauley, Jr., Commissioner of Precinct 4;
Karen McQueen, County Clerk.
The attached sheet contains the names of the citizens and
officials that were in attendance.
Commissioner Mallard gave the invocation and then led the
pledge of allegiance.
Under citizen input/and or concerns, the following spoke:
Mary Jo Chapel
a) She is the owner of a wrecker service and is in favor
of setting fees, but thinks that the fee is incorrect.
Mileage needs to be included in the figure. She feels
there should have been a hearing with input from owners.
She went on to say that she does agree that price gauging
occurs and fee caps should be set but the caps were set
too low. She predicts gasoline will go up again as will
the cost of living.
Vol hq Page q
Commissioners Court meeting March 3, 2009 2
The Court heard a presentation by Paul Kaspar with the
City of Bryan on their capital improvement projects. This is
a five (5) year project and he asked the Court for feedback on
needed projects.
The next matter before the Court was consideration of a
Telecommunications Work Order with Texas A&M University for
the installation of conduit and fiber optic cabling to the
Precinct 3 Justice of the Peace, Precinct 3 building. The cost
for this service is $18,105.00. The Texas A&M
Telecommunications Division will provide the work and the TAMU
Academy for Advanced Telecommunication & Learning Technologies
will provide oversight. On motion by Commissioner Mallard,
seconded by Commissioner Peters, the Court voted unanimously
to approve the work order.
The Court next considered Budget Amendment #08/09-22.1
through 22.4 that would reallocate funds for the General
Capital Improvement Fund, County Attorney, Brazos County Grant
Fund-Brazos County CUEP Grant; transfer funds from Contingency
and JP Technology fund to the Capital Improvement Fund. On
motion by Commissioner Cauley, seconded by Commissioner
Peters, the Court voted unanimously to approve the budget
amendment as submitted. A copy each amendment is attached.
The next matter before the Court was consideration of a
Vol ( Page
Commissioners Court meeting March 3, 2009 3
request from the District Attorney's Office for permission to
continue the Victim Assistance Coordinator position as part
time. This is temporary and continues to be at no cost to the
county. On motion by Commissioner Peters, seconded by
Commissioner Wassermann, the Court voted unanimously to
approve the request.
The Court proceeded to consider the change of status of
employees as submitted on the attached Personnel Action
Requests. On motion by Commissioner Wassermann, seconded by
Commissioner Cauley, the Court voted unanimously to approve
the changes as submitted.
The Court next considered the following Claims as
submitted by the County Treasurer for payment:
7059449 through 7059681
On motion by Commissioner Peters, seconded by Commissioner
Cauley, the Court voted unanimously to approve the Claims as
submitted.
The Court next considered cancellation of the regular
session of Commissioners Court scheduled for March 10, 2009
due to there not being a quorum available on that date. On
motion by Commissioner Peters, seconded by Commissioner
Wassermann, the Court voted unanimously to cancel the regular
Vol Cf~ Page
Commissioners Court meeting March 3, 2009 4
session of the Commissioners Court scheduled for March 10,
2009.
The next matter before the Court was consideration of an
Architect Services Contract between Brazos County and Fred A.
Patterson, Jr. dba Patterson Architects, Inc. whereby the
Architect agrees to provide the County with professional
services which include preliminary design, final design, RFP
preparations and evaluations, and construction. The cost to
Brazos County is approximately $628,050.00. On motion by
Commissioner Peters, seconded by Commissioner Cauley, the
Court voted unanimously to approve the Architect Services
Contract. A copy is attached.
The next matter for consideration by the Court was a
request submitted by Tom Quarles, Director of the Expo Complex
to attend the International Association of Assembly Managers'
Conference and Trade Show in Boston, Massachusetts July 25
through 27, 2009. On motion by the County Judge, seconded by
Commissioner Peters, the Court voted unanimously to grant the
request from the Director of the Expo Complex and approved
payment of out of state travel expense for Tom Quarles.
The next matter for consideration was approval of tax
refund applications from the following individuals and/or
companies:
Vol Page 7
Commissioners Court meeting March 3, 2009 5
a. Hazel Todd (2), payment in error $41.43, $157.56
b. Mary Sue McRae, over payment $100.00
c. LPS Property Tax Service, over payment $810.00
d. Citifinancial, over payment $151.05
e. Brandon Berry Construction, Inc., over payment
$180.81
f. 7711 Employees Royalty, over payment $366.47
g. Felix Fernandez-Ramos, over payment $29.41
h. Fredriko's Mexican Bar & Grill, over payment
$235.46
i. Shoe Daze, over payment $86.51
j. Vision Insight, over payment $11.78
k. Angonia Printing, over payment $159.75
1. Pete's Corner, over payment $153.53
m. Joe Tsung-Chow Su & Hui Fang Huang, over payment
$2,401.00
n. A. W. Jeanes, Jr., over payment $264.72
On motion by Commissioner Peters, seconded by Commissioner
Cauley, the Court voted unanimously to approve the tax refund
applications.
The Court next considered a requisition in the amount of
$628,050.00 to Patterson Architects for architectural and
Engineering Services for the remodeling of the Brazos County
Courthouse. On motion by Commissioner Peters, seconded by
Commissioner Cauley, the Court voted unanimously to approve
the requisition.
The next matter before the Court was consideration of a
requisition to Texas A&M University in the amount of
$18,105.00 for the supply and installation of fiber optic
cabling and conduit, and the boring of necessary roads. On
motion by Commissioner Mallard, seconded by Commissioner
Vol Page
Commissioners Court meeting March 3, 2009 6
Cauley, the Court voted unanimously to approve the
requisition.
The Court next considered authorizing work outside of
county rights-of-way for the health, safety and welfare of the
general public. The Road and Bridge Department requested
permission to enter the private property of Charles Cotrone on
Cotrone-Dix Road in Precinct 4 to remove some large trees. On
motion by Commissioner Cauley, seconded by Commissioner
Peters, the Court voted unanimously to authorize the work.
The Court next considered authorizing work outside of
county rights-of-way for the health, safety and welfare of the
general public. The Road and Bridge Department requested
permission to enter the private property of Tony Varisco on
Cotrone-Dix Road in Precinct 4 to create a detour to allow
county equipment access to a work site. On motion by
Commissioner Cauley, seconded by Commissioner Peters, the
Court voted unanimously to authorize the work.
The Court next considered authorizing work outside of
county rights-of-way for the health, safety and welfare of the
general public. The Road and Bridge Department requested
permission to enter the private property of Lee Fazzino on
Cotrone-Dix Road in Precinct 4 to create a detour allowing
county equipment access to a work site. On motion by
Vol IPage 9
Commissioners Court meeting March 3, 2009 7
Commissioner Cauley, seconded by Commissioner Mallard, the
Court voted unanimously to authorize the work.
The Court next considered authorizing work outside of
county rights-of-way for the health, safety and welfare of the
general public. The Road and Bridge Department requested
permission to enter the private property of Norman Ellison on
Jack Creek Road in Precinct 2 to replace a 90 degree inlet for
lake spillway under Jack Creek Road. On motion by Commissioner
Peters, seconded by Commissioner Wassermann, the Court voted
unanimously to authorize the work.
The next matter before the Court was consideration of a
payment authorization in the amount of $27,500.00 to Patterson
Architects for the Architectural Pre-Design Services for the
remodeling of the Brazos County Courthouse. On motion by
Commissioner Peters, seconded by Commissioner Cauley, the
Court voted unanimously to approve the payment authorization.
The Court acknowledged receipt of the monthly reports in
February 2009.
The Court acknowledged receipt of the Summary of 2008
Racial Profiling Statistical Report from the office of
Constable, Precinct 1.
Under announcement of interest items and possible future
agenda topics the following spoke:
Vol q Page 16
Commissioners Court meeting March 3, 2009 8
Clyde Collins, Chief Deputy
a) Said that there are 561 inmates in jail, 74
are in the Anderson County Jail, 36 are on
electronic monitoring and 31 are awaiting
their monitors.
Chuck Frazier, Emergency Management
Coordinator
a) Spoke on the KBD Index and the current
drought conditions.
Donald Lampo, Constable, Precinct 2
a) Spoke on Go Texas. He introduced William
Rooney who received a $15,000.00
scholarship to A&M in poultry science. A
second scholarship was also given to a
student who went to Texas Tech.
County Judge
a) He showed the Court a flag that 4H
presented to him at the last meeting.
There was no citizen input and/or concerns.
Under Agency/Board/Committee reports by Court members,
the following spoke:
Commissioner Mallard
a) He went to Austin last week to attend a
meeting on the High Speed Rail. A new
member was added to the group. They are
making headway in Austin.
There being no further business to come before the Court,
the meeting was adjourned.
Vol _ Page d
The foregoing minutes of the Commissioners Court meeting held
March 3, 2009 have been examined and are approved in open
Court this the j~ day of 2009, in Bryan,
Brazos County, Texas.
Randy SAS' Lloyd W ssermann
County Judge Commissioner, Precinct 1
Duane Peters Kenny Malla
Commissioner, Precinct 2 Commissione , Precin 3
1
Ca ey C ley, Jr.
Commissioner, Precinct 4
Attest:
a n McQueen l
County Clerk ~
Vol Page I:
BRAZOS COUNTY COMMISSIONERS COURT
Meeting one , 2009 @ .
Name Organization / Department
t l~l ~ ~ AN L t.~ L•
(,UAC- Lk RLUJII
c~
N-t
r ~
PAGE of
1 . 13
BRAZOS COUNTY COMMISSIONERS COURT
Meeting on / y (a'--~ 2009
Name Organization / Department
4-ALr,w RA-Eq tic
TT-
e-
a#, e y All
8-
PAGE of
1c]
BRAZOS COUNTY, TEXAS
BUDGET AMENDMENT(S) FOR THE 2008-2009 BUDGET YEAR
NO. 08/09 - 22.1 thru 22.4
On this the 3`d day of March 2009 at a regular meeting of the Commissioners' Court, the following
members were present:
Randy Sims, County Judge, Presiding
Lloyd Wassermann, Commissioner, Precinct 1
E. Duane Peters, Commissioner, Precinct 2
G. Kenny Mallard, Commissioner, Precinct 3
Carey Cauley, Jr., Commissioner, Precinct 4
Karen McQueen, County Clerk
The following proceedings were held:
THAT WHEREAS, on 3 March 2009 the Court heard and approved a budget amendment for the
2008-2009 budget year for Brazos County, Texas; and
WHEREAS, an expenditure is necessary due to the necessity to meet unusual and unforeseen
conditions which could not be reasonably included in the original budget adopted 19 September 2008, the
following amendment(s) to the original budget are hereby authorized, as described on the attached page(s).
ADOPTED AND APPROVED this the 3`a day of March 2009.
THE COMMISSIONERS COURT OF BRAZOS COUNTY, TEXAS.
By:
Randy ' s, County Judge
Original: County Clerk's Office and
attached to the original budget
Copies: County Auditor
County Treasurer
County Budget Officer
Commissioners' Court Minutes
110 :
BRAZOS COUNTY, TEXAS
BUDGET AMENDMENTS
No. 08109 - 22.1
3!312009
FUND DIV ACCT PROJ DR/CR ACCOUNT NAME Increase Decrease
0100 11001500 61130000 CR Contingency - General Fund 16,978.00
0100 91110000 DR Transfer to Capital Im rovement Fund 16,978.00
4500 49028000 CR Transfer from General Fund 16,978.00
4500 63000500 80205000 DR Computer - Network Costs 16,978.00
2400 24005300 61130000 CR Contingency- JP Technol oy Fund 2,000.00
2400 24005300 80205000 DR Computer - Network Costs 2,000.00
r
General Fund, General Capital Improvement Fund and JP Technology Fund
To reallocate funds to allow for the fiber connection to be installed in the Justice of the Peace Pct #3 building. Funding is being
requested from both the General Fund-Contin enc for $16,978 and the Justice of the Peace Pct #3 will be contributin $2,000.00
from his share of the JP Technolo Fund.
x 2 _
Dearkrnent tApP,,~oval Date
k
Date . , 4 s .~2,f26~2009 _
Co my ~u a Approuaf _D t .
BRAZOS COUNTY, TEXAS
BUDGET AMENDMENTS
No. 08109 - 22.2
3/3/2009
FUND DIV ACCT PROD DR/CR ACCOUNT NAME Increase Decrease
4500 63000500 60360000 CR Furniture 2,268.80
4500 63000500 67342000 DR Furniture 2,268.80
General Capital Improvement Fund
To reallocate funds to the furniture account over $500 to correct/ account for the cost in the proper account.
The District Attorney was allocated a total of $46,000 for furniture in the 2009 approved budget. This is to utilize the funding
set aside for the de artment.
D partment Approval Date
By: r , if
.,Prepared
/
Date: 2/2612009
County Ju a Approval Date
BRAZOS COUNTY, TEXAS
BUDGET AMENDMENTS
No. 08/09 - 22.3
3/3/2009
FUND DIV ACCT PROJ DR/CR ACCOUNT NAME Increase Dec!410.00
0100 18000100 65550000 CR Radio Maintenance 0100 18000100 65950000 CR Vehicle Maintenance 0100 18000100 60500000 DR Office E ui ment 810.00
Coun Attorney
To reallocate funds to allow for the purchase of two 2 resentation rolling stands for the TVs, com uter la to s and DVD la erE
to show video evidence durin trials handled in the Coun Courts at Law.
pepart- ntAA p oval s _
Prepared By l
X2-126 200,9 y/
Dane ' _
GountyJud ApPx~0val'~~..,__ r~ Date_~--
0 Iry ~
BRAZOS COUNTY, TEXAS
BUDGET AMENDMENTS
No. 08/09 - 22.4
3/3/2009
FUND DIV ACCT PROJ DR/CR ACCOUNT NAME Increase Decrease
3000 1831000 51620000 DR Hourly - Overtime 20,296.00
3000 1831000 53100000 DR Social Security 2,030.00
3000 1831000 53200000 DR Retirement 3,044.00
3000 1831000 71400000 CR Peace Officers 22,850.00
3000 1831000 71710000 CR Video a her 2,520.00
Brazos County Grant Fund- Brazos County CUDEP GRANT
To reallocate funds from Contractual Services to Salary and wages to a Peace Officers and Video Recorders.
as employees and not contractual workers as re uired b the IRS.
;,Department Approv I Date
Prepared By: ifj~
Date: 2/27/2009`
County Ju a Approval Date
lr. ,
n f E. a i,;
PERSONNEL
CHANGE OF STATUS REQUESTS
Commissioner Court Date: March 3, 2009
Department Submitting Information: Human Resources
Purpose of Submissions: Consider and Take Action on Change Requests
Department Submitting Employee Request Action Requested
Request(s) Applies To
Building Maintenance Guevara, Jesus New Hire
District Attorney Carter, Melissa Other-Temporary Reclassification
District Clerk Morgan, Lori Transfer with in Department
Juvenile Services Carter, Tommy Resignation
Sherriff's Office- Jail Thomas, Luke New Hire
Tax Office Leatherwood, Kathleen Resignation
Approved in Commissioners' Court: March 3,2009:
County Judge's or Commissioner's Signature:
(This Copy to be attached to minutes)
ARCHITECT SERVICES CONTRACT ID
This Contract is between the County of Brazos County, Texas, ("County")
and Fred A. Patterson Jr. dba Patterson Architects, Inc. ("Architect"), whereby
the Architect agrees to provide the County with certain professional services as
described herein and the County agrees to pay the Architect for those services.
ARTICLE I
Scope of Services
1.01 In consideration of the compensation stated in paragraph 2.01 herein
below, the Architect agrees to provide the County with the professional services
as described in Exhibit "A", the Scope of Services. Any services requested by
the County which exceed the Scope of Services shall be compensated in
accordance with the schedule provided in the attached Exhibit "B". All such
additional services must be approved in writing in advance by the County.
ARTICLE II
Payment
2.01 In consideration of the Architect's provision of the professional services
in compliance with all terms and conditions of this contract, the County shall
pay the Architect according to the terms set forth in Exhibit "B" except in the
event of a duly authorized change order, approved by the County as provided in
this Contract.
ARTICLE III
Time of Performance
3.01 The Architect shall exercise a degree of care and diligence in the
performance of all services under this contract in accordance with the
professional standards prevailing among Architects in the location in which
the Architect practices or Brazos County, Texas, whichever is the higher
standard, skilled in design for projects of similar scope, and all of the Architect
services shall be performed as expeditiously as is consistent with said
standards and the orderly progress of the work.
3.02 Time is of the essence of this Contract. The Architect shall be
prepared to provide the professional services in the most expedient and
efficient manner possible in order to complete the work in a timely manner.
The time limits established by this schedule over which Architect has control
shall not be exceeded without written approval from the Commissioner's
Court. The County must respond in a timely manner regarding requirements
for and limitations on the project order for the Architect to stay on schedule.
3.03 The Architect's services consist of all of the services required to be
performed by the Architect, Architect employees and Architect consultants
under the terms of this contract. Such services include normal civil,
structural, mechanical and electrical engineering services, and any other
design services that are normally or customarily furnished and reasonably
necessary for the Project. The Architect shall contract and employ, at his
expense, consultants necessary for the design of the Project, and such
consultants shall be licensed as required by the State of Texas and.approved
in writing by the County.
3.04 The Architect shall designate a principal of the firm reasonably
satisfactory to the County who shall, so long as employed by the Architect and
acceptable to the County, remain in charge of professional services through
completion of the design and be available for general consultation throughout
the Project. Any replacement of that principal shall be approved in writing
(which shall not be unreasonably withheld) by the County, prior to
replacement.
3.05 The Architect shall be responsible for the coordination of all drawings
and design documents used on the Project. The Architect shall also be
responsible for the completeness and accuracy of all drawings and
specifications for their compliance with all applicable codes, ordinances,
regulations, laws and statutes.
3.06 The Architect's evaluations of the preliminary estimates of construction
cost shall be based on Architect's best judgment as a design professional
familiar with the construction industry, however, Architect is not a general
contractor and is not responsible for construction cost accuracy.
ARTICLE IV
Conceptual Design
4.01 Upon the Architect's approval from Commissioner's Court, a letter of
authorization to commence planning, the Architect shall meet with each
department of the County that is included in the design or re-design for the
purpose of determining the nature of the Project. The Architect shall use the
County's Long Range Planning documents including the "Final Draft of the
Needs Assessment and Master Plan dated 4/7/05" to assist in space
requirements. The County designates Pat Howard, Brazos County Purchasing
Agent, as representative to act as the contact person on behalf of the County.
4.02 The Architect shall determine the County's needs with regard to the
Project, including, but not limited to, tests, analyses, reports, site evaluations,
needs surveys, comparisons. Architects shall verify the observable existing
conditions of the Project and verify any existing as-built drawings. The
Architect shall prepare a detailed design phase schedule which includes all
review and approval periods during the schematic design, design development
and construction document phases.
4.03 The Architect shall prepare a conceptual design that shall include
schematic layouts, surveys, sketches and exhibits demonstrating the
considerations involved in the Project. The conceptual design shall contemplate
compliance with all applicable laws, statutes, ordinances, codes and
regulations. Upon the County's request, the Architect shall meet with the
Commissioner's Court or appointed Committee to make a presentation of his or
her report.
ARTICLE V
Preliminary Design
5.01 The County shall direct the Architect to commence work on the
preliminary design by approval of the Commissioner's Court. The Architect
shall meet with the County for the purpose of determining the extent of any
revisions to the Conceptual Design. The County shall direct the Architect to
commence work on the Preliminary design of the Project by sending to the
Architect a "letter of authorization" to begin work on the preliminary design
phase of the Project.
5.02 The Architect shall prepare the preliminary design of the Project,
including, but not limited to, the preliminary drawings and specifications and
other documents to fix and describe the character of the Project as to
architectural, structural, mechanical and electrical systems, materials and
such other elements as may be appropriate. The Architect shall submit to the
County a detailed design and estimate of the construction costs of the Project,
based on current area, volume, or other unit costs.
5.03 Upon completion of the preliminary design of the Project, the Architect
shall meet with approved committee for Brazos County to make a presentation
of the preliminary design of the Project. The Architect shall provide an
explanation of the preliminary design and cost estimate and shall verify that, to
the best of Architect's belief and if the Project requirements and construction
can be completed within the project budget and schedule.
ARTICLE VI
Final Design
6.01 The County shall direct the Architect to commence work on the final
design of the Project by sending to the Architect a "letter of authorization" to
begin work on the final design phase of the Project. Upon receipt of the Letter
of Authorization to proceed with final design of the Project, the Architect shall
immediately prepare the final design, including, but not limited to, the bid
documents, contract, drawings, and specifications, to fix and describe the size
I _;.3
and character of the Project as to structural, mechanical, and electrical
systems, materials, and such other elements as may be appropriate. The final
design of the Project shall comply with all applicable laws, statutes,
ordinances, codes and regulations.
6.02 Upon approval of the final design, the final design will be sufficient for
construction of the Project.
6.03 The Architect shall cooperate with Purchasing to obtain bids for the
construction contract between the County and the Contractor. The Architect
hereby agrees that no changes, modifications, supplementations,
alterations, or deletions will be made to the Project unless warranted by
necessity and approved by the Commissioner's Court.
6.04 The Architect shall provide the County with complete contract
documents sufficient to be advertised for bids by the County. The contract
documents shall include the design and specifications and other changes that
are required to fulfill the purpose of the Project. Upon completion of the final
design of the Project, with the submission of the complete contract documents,
and upon request of the County, the Architect shall meet with the approved
Committee for Brazos County and/or the Commissioner's Court to present the
final design of the Project. The Architect shall provide an explanation of the
final design and cost estimate.
ARTICLE VII
RFP Preparations & Evaluation
7.01 The Architect shall assist the County in advertising for and obtaining
bids or negotiating proposals for the construction of the Project. Upon request,
the Architect shall meet with the approved Committee and/or the
Commissioner's Court to present, and make recommendations on the bids
submitted for the construction of the Project.
7.02 The Architect shall review the construction Contractors' bids, including
subcontractors, suppliers, and other persons required for completion of the
Project. The Architect shall evaluate each bid and provide these evaluations to
the County along with a recommendation on each bid. If the lowest bid for the
construction of the Project exceeds by more than 5% the final cost estimate set
forth in the final design of the Project, then the Architect, at his sole cost and
expense, shall revise the construction documents so that the total
construction costs of the Project will not exceed by more than 5% the final cost
estimate contained in the final design of the Project.
7.03 Where substitutions are requested by a construction contractor, the
Architect shall review the substitution requested and approve or disapprove
such substitutions. f I9
_
ARTICLE VIII
Construction
8.01 The Architect shall advise and consult with, the County (1) during
construction, and (2) at the County's direction from time to time during the
correction, or warranty, period described in the construction contract. The
Architect shall have authority to act on behalf of the County only to the extent
provided in this Agreement unless modified by written instrument.
8.02 The Architect shall make visits to the site, with a frequency appropriate
to the stage of construction and scope of the Project, to observe the progress
and quality of the executed work of the construction contractor and his
subcontractors and to determine in general if such work is proceeding in
accordance with the contract documents. The Architect shall periodically
review the as-built drawings for accuracy and completeness, and shall report
his or her findings to the County.
8.03 The Architect shall keep the County informed of the progress and
quality of the work by meeting weekly with the approved County Committee.
The Architect shall exercise the utmost care and diligence in discovering and
promptly reporting to the County any defects or deficiencies in such work and
shall disapprove or reject any work failing to conform to the contract
documents.
8.04 The Architect shall review and approve shop drawings and samples, the
results of tests and inspections, and other data that each construction
contractor or subcontractor is required to provide. The Architect's review and
approval shall include a determination whether the work conforms with the
requirements of the contract documents.
8.05 The Architect shall determine the acceptability of substitute materials
and equipment that may be proposed by construction contractors or
subcontractors. The Architect shall also receive and review maintenance and
operating instruction manuals, schedules, guarantees, and certificates of
inspection, which are to be assembled by the construction contractor in
accordance with the contract documents.
8.06 The Architect shall issue all instructions of the County to the
construction contractor as well as interpretations and clarifications of the
contract documents pertaining to the performance of the work. The Architect
shall interpret the contract documents and judge the performance by the
contractor constructing the Project, and the Architect shall, within a
reasonable time, render such interpretations and clarifications as deemed
necessary for the proper execution and progress of the Work. The Architect
shall receive no additional compensation for providing clarification of the
Drawings and Specifications. _
sr,
8.07 The Architect shall review the amounts owed to the construction
contractor and recommend to the County, in writing, payments to the
construction contractor of such amounts. The Architect's recommendation of
payment, being based upon the Architect's on-site inspections and experience
and qualifications as a design professional, shall constitute a recommendation
by the Architect to the County that the quality of such work is in accordance
with the contract documents. and that the work has progressed to the point
reflected in Architect's recommendation for payment.
8.08 Upon notification from the construction contractor that the Project is
substantially complete, the Architect shall conduct an inspection of the site to
determine if the Project is substantially complete. The Architect shall prepare a
checklist of items that shall be completed prior to final acceptance. Upon
notification by the construction contractor that the checklist items designated
by the Architect for completion have been completed, the Architect shall
inspect the Project to verify final completion.
8.09 The Architect shall not be responsible for the work of the construction
contractor or any of the subcontractors. This provision shall not alter the
Architect's duties to the County arising from the performance of the Architect's
obligations under this Contract.
8.10 The Architect shall conduct at least one on-site inspection during the
warranty period and shall report to the County as to the continued
acceptability of the work.
8.11 The Architect shall not execute change orders on behalf of the County or
otherwise alter the financial scope of the Project without an advance, written
authorization from the County.
8.12 The Architect shall perform all of his or her duties under this Article VIII
so as to not cause any delay in the progress of construction of the Project.
8.13 The Architect shall assist the construction contractor and County in
obtaining an Occupancy Permit by accompanying governing officials during
inspections of the Project if requested to do so by the County.
ARTICLE IX
Change Orders & Documents & Materials
9.01 No changes shall be made, nor will invoices for changes, alterations,
modifications, deviations, or extra work or services be recognized or paid
except upon the prior written order from authorized personnel of the County.
The Architect shall not execute change orders on behalf of the County or
otherwise alter the financial scope of (the Project.
9.02 Written change orders may be approved by Commissioner's Court if the
amount owed to Architect or Contractor changes. Change Orders that do not
alter the approved budget shall be approved by the committee appointed by
Commissioner's Court. Any request by the Architect for an increase in
the Scope of Services or an increase in the amount listed in paragraph
2.01 of this Contract shall be made and approved by the County prior
to the Architect providing such services or the right to payment for
such additional services shall be waived. If there is a dispute between the
Architect and the County respecting any service provided or to be provided
hereunder by the Architect, including a dispute as to whether such service in
addition to the Scope of Services included in this Contract, the Architect
agrees to continue providing on a timely basis all services to be provided by
the Architect hereunder, including any service as to which there is a dispute.
9.03 The Architect shall furnish the County four sets of plans and
specifications. It is hereby agreed that additional copies shall be provided to
the County at the County's expense. The Architect shall provide the County
two sets of reproducible drawings in DWG or other reproducible format that
clearly show all the changes made during the construction process, based
upon the marked-up prints, drawings, and other data furnished by the
construction contractor to the Architect. The Architect shall provide copies of
documents, computer files if available, surveys, notes, and tracings used or
prepared by the Architect. The foregoing documentation, the work product,
and other information in the Architect's possession concerning the Project
shall be the property of the County from the time of preparation. The Architect
shall also furnish one set of digital files representing the final as-built
drawings.
9.04 The Architect shall prepare Change, Orders and Construction Change
Directives for the County's approval and execution in accordance with the
Contract Documents. The Architect may authorize minor changes in the Work
not involving an adjustment in the Contract Sum or an extension of the
Contract Time which are consistent with the intent of the Contract
Documents. If necessary, the Architect shall prepare, reproduce and
distribute Drawings and Specifications to describe Work to be added, deleted
or modified.
9.04.1 The Architect shall review properly prepared timely requests by the
County or Contractor for changes in the work, including adjustments shall
be accompanied by sufficient supporting data and information to permit the
Architect to make a reasonable determination without extensive investigation
or preparation of additional drawings or specifications. If the Architect
determines that requested changes in the work are not materially different
from the requirements of the Contract Documents, the Architect may issue an
order for a Minor Change in the Work or recommend to the County that the
requested change be denied.
9.04.2 If the Architect determines that implementation of the requested
changes would result in a material change to the Contract that may cause an
adjustment in the Contract Time or Contract Sum, the Architect shall make a
recommendation to the County, who may authorize further investigation of
such change. Upon such authorization, and based upon information
furnished by the Contractor, if any, the Architect shall estimate the additional
cost and time that might result from such change including any additional
costs attributable to a changes in services of the Architect. With the County's
approval, the Architect shall incorporate those estimates into a Change Order
or other appropriate documentation for the County's execution or negotiation
with the Contractor.
9.04.3 The Architect shall maintain records relative to changes in the work.
ARTICLE X
Project Completion
10.01 The Architect shall conduct inspections to determine the date or dates
of substantial completion and the date of final completion, shall receive from
the Contractor and forward to the County's review and records, written
warranties and related documents required by the contract documents and
assembled by the Contractor, and shall issue a final. certificate for Payment
based upon a final inspection indicating the work complies with the
requirements of the contract document.
10.02 The Architect's inspection shall be conducted with the County's
representative for the conformance of the work with the requirements of the
contract documents and to verify the accuracy and completeness of the list
submitted by the Contractor of work to be completed or corrected.
10.03 When the work is found to be substantially complete, the Architect
shall inform the County about the balance of the contract sum remaining to be
paid the Contractor, including any amounts needed to pay for final completion
or correction of the work.
10.04 The Architect shall receive from the Contractor and forward to the
County: (1) consent of surety or sureties, if any to reduction in or partial
release of retainage or the making of final payment and (2) affidavits, receipts,
releases and waivers of liens or bonds indemnifying the Owner against liens.
ARTICLE XI
Warranty, Indemnification & Release
11.01 As an experienced and qualified design professional, the Architect
warrants that the information provided by the Architect reflects high
professional and industry standards, procedures, and performances. The
Architect warrants the design preparation of drawings, the designation or
selection of materials and equipment, the selection and supervision of
personnel, and the performance of other services under this Contract,
pursuant to a high standard of performance in the profession. The Architect
warrants that the Contractor will exercise diligence and due care and perform
in a good and workmanlike manner all of the services pursuant to this
Contract. Approval of the County shall not constitute, or be deemed, a release
of the responsibility and liability of the Architect, its employees, agents, or
associates for the exercise of skill and diligence to promote the accuracy and
competency of their designs, information, plans, specifications or any other
document, nor shall the County's approval be deemed to be the assumption of
responsibility by the County for any defect or error in the aforesaid documents
prepared by the Architect or the Architect's employees, associates, agents, and
subcontractors.
11.02 The Architect shall promptly correct any defective designs or
specifications furnished by the Architect at no cost to the County. The
County's approval, acceptance, use of, or payment for, all or any part of the
Architect's services hereunder or of the Project itself shall in no way alter the
Architect's obligations or the County's rights hereunder.
11.03 In all activities or services performed hereunder, the Architect shall be
deemed an independent contractor, and not an agent or employee of the
County. The Architect and his or her employees are not the agents, servants,
or employees of the County. As an independent contractor, the Architect shall
be responsible for the professional services and the final work product
contemplated under this contract. Except for materials furnished by the
County, the Architect shall supply all materials, equipment, and labor
required for the professional services to be provided under this contract.
11.04 The Architect must at all times exercise reasonable precautions on
behalf of, and be solely responsible for, the safety of his or her employees for
the project.
11.05 Indemnity/ Comparative Negligence: The Architect shall indemnify the
County only to the extent of the liability that was caused by the Architect. To
the fullest extent by law, the Architect agrees to and shall indemnify, hold
harmless, and defend the County, its officers, agents, and employees from and
against any and all claims, losses, damages, causes of action, suits, and
liability, of every kind including all expenses of litigation, court costs, and
attorney's fees for injury to or death of any person, for damages to any
property, or for any breach of contract, arising out of or in connection with any
negligent services by the Architect under this Contract, provided and only to
the extent that any such claim, loss, damage, cause of action, suit, or liability
is caused in whole or in part by an act or omission of the Architect.
11.06 The Architect cannot and does not warrant or guarantee that the
County's project will comply with interpretations of Americans with Disabilities
Act (ADA) requirements and/or requirements of other federal or state laws as
they apply to the project. The Architect will submit the construction
documents to the Texas Department of Licensing and Regulation,
Architectural Barriers Department (TDLR) for review of handicap compliance.
Correspondence to and from TDLR will be provided to the County. The cost for
project registration, review of construction documents and post construction
inspection will' be the responsibility of the County.
11.07 It is understood that the existing building may contain asbestos or
products containing asbestos, as substance known to present health hazards.
The County acknowledges that the Architect's scope of services for this project
does not include any services related in any way to asbestos.
ARTICLE XII
Insurance
12.01 The Architect shall procure and maintain required insurance at his sole
cost and expense for the duration of this agreement.
ARTICLE XIII
Use of Drawings, Specifications and Other Documents
13.01 The drawings, specifications and other documents prepared by the
Architect for this project shall become the property of the County whether or
not the project is completed. The County shall be furnished and permitted to
retain reproducible copies and electronic versions of Architect's drawings,
specifications and other documents.
13.02 The documents prepared by the Architect may be used as a prototype
for other facilities by the County. The County may elect to use the Architect to
perform the site adaptation and other architectural services involved in reuse of
the prototype. If so, the Architect is obligated to perform the work for an
additional compensation that will fairly compensate the Architect and required
consultants only for the additional work involved. It is reasonable to expect
that the fair additional compensation will be significantly less than the fee
provided for under this contract.
13.03 In the event of termination of this agreement for any reason, the County
shall receive all original documents prepared to the date of termination and
shall have the right to use those documents and any reproductions in any way
necessary to complete the Project.
13.04 Only the details of the drawings relating to this project may be used by
the Architect on other projects, but they shall not be used as a whole without
31
written authorization by the County. The County's furnished forms, conditions,
and other written documents shall not be used on other projects by the
Architect.
ARTICLE XIV
Termination
14.01 The County may terminate the Architect at any time upon thirty (30)
calendar days written notice. Upon the Architect's receipt of such notice, the
Architect shall cease work immediately. The Architect shall be compensated for
the services performed prior to the termination date.
14.02 If, through any cause, the Architect fails to fulfill his or her obligations
under this Contract, or if the Architect violates any of the agreements of this
Contract, the County has the right to terminate this Contract by giving the
Architect five (5) calendar days written notice to the Architect. The Architect
will be compensated for the services performed before the termination date.
14.03 No term or provision of this Contract shall be construed to relieve the
Architect of liability to the County for damages sustained by the County
because of any breach of contract and/or negligence of the Architect.
ARTICLE XV
Mediation
15.01 Any claim dispute or other matter in question arising out of or related to
this agreement shall be subject to mediation as a condition precedent to
arbitration or the institution of legal or equitable proceedings by either party.
If such matter relates to or is the subject of a lien arising out of the Architect's
services, or a disputed and unpaid sum for such services, the Architect may
proceed in accordance with applicable law to comply with the lien notice or
filing deadlines prior to resolution of the matter by mediation or by arbitration.
15.02 The County and Architect shall endeavor to resolve claims, disputes and
other matters in question between them by mediation which, unless the parties
mutually agree otherwise, shall be in accordance with the Construction
Industry Mediation Rules of the American Arbitration Association currently in
effect. Request for mediation shall be filed in writing with the other party to
this Agreement and with the National Mediation Academy of Texas. The
request may be made concurrently with the filing of a demand for arbitration
but, in such event, mediation shall proceed in advance of arbitration or legal or
equitable proceedings, which shall be stayed pending mediation for a period of
60 days from the date of filing, unless stayed for a longer period by agreement
of the parties or court order.
15.03 The parties shall share the mediator's fee and any filing fees equally.
The mediation shall be held in the place where the Project is located, unless
another location is mutually agreed upon. Agreements reached in mediation
shall be enforceable as settlement agreements in any court having jurisdiction
thereof.
ARTICLE XVI
Miscellaneous Terms
16.01 This Contract has been made under and shall be governed by the laws
of the State of Texas. The parties agree that performance and all matters
related thereto shall be in Brazos County, Texas.
16.02 Notices shall be mailed to the addresses designated herein or as may be
designated in writing by the parties from time to time and shall be deemed
received when sent postage prepaid U.S. Mail to the following addresses:
County of Brazos
Attn: Pat Howard, Purchasing Agent
200 S. Texas Ave., Suite 352
Bryan, TX 77803
Architect:
Fred A. Patterson Jr. dba Patterson Architects, Inc.
701 S. Texas Ave.
Bryan, Texas 77803
16.03 No waiver by either party hereto of any term or condition of this
Contract shall be deemed or construed to be a waiver of any other term or
condition or subsequent waiver of the same term or condition.
16.04 This Contract represents the entire and integrated agreement between
the County and the Architect and supersedes all prior negotiations,
representations, or agreements, either written or oral. This Contract may only
be amended by written instrument approved and executed by the parties.
16.05 This Contract and all rights and obligations contained herein, may not
be assigned by either party without the prior written approval of the other.
16.06 If any provision of this contract shall be held to be invalid or
unenforceable for any reason, the remaining provisions shall continue to be
valid and enforceable. If a court of competent jurisdiction finds that any
provision of this contract is invalid or unenforceable, but that by limiting such
provision it may become valid and enforceable, then such provision shall be
deemed to be written, construed, and enforced as so limited.
16.07 The Architect and his or her employees must comply with all applicable
federal and state laws and with all applicable rules and regulations
promulgated by local, state, and national boards, bureaus, and agencies. The
Architect must obtain all necessary permits and licenses required.
16.08 The Architect acknowledges that he or she has read, understood, and
intend to be bound by the terms and conditions of this Contract.
16.09 This contract will be effective when signed by the Architect and approved
and signed by Commissioner's Court.
16.10 Notice of Indemnification. County and Architect hereby acknowledge
and agree that this contract contains certain indemnification obligations and
covenants.
16.11 The Texas Board of Architectural Examiners, P. O. Box 12334, Austin,
Texas 78711-2337 or 33 Guadalupe, Suite 2-350, Austin, Texas 78701-3943,
Telephone 512/305-9000, has jurisdiction over individuals licensed under the
Architects Registration Law, Texas Civil Statues Article 249a.
Approved: Approved:
Patterson Architects, Inc. Brazos County
Fred A. Patterson Jr. Randy Sims, Br s o Judge
Signature: Signature:
Date: -2'~~0 Date: 3(n7ln9
Exhibit "A"
Scope of Services
The following offices are currently scheduled to remain in the Brazos County Courthouse during
renovation:
85`h District Court Offices and Courtroom
272" District Court Offices and Courtroom
361St District Court Offices and Courtroom
District Attorney Offices
County Attorney Offices
County Court at Law #1 Offices and Courtroom
County Court at Law #2 Offices and Courtroom
District Clerk Offices
County Clerk Offices
Court Master Offices
Jury Services Office
Magistrate Office
Cluster Court .
Services under this contract for the renovation of the entire Courthouse will be provided through
Conceptual Design to assist the County in determining if the existing building will support the
proposed space needs identified in the 2005 Needs Assessment Study and in meeting with the
current users of the existing facility (department heads, appointed and elected officials).
Remaining Basic Services (Preliminary Design through Construction Administration) will be
provided for selected phases (areas of work within the Courthouse) as approved by the
Commissioners Court or appointed Committee.
Basic Services -
"Basic Services" to be provided by Patterson* Architects for this project include the following:
A. Conceptual Design for the entire Courthouse (125,650 GSF / 91,950 NSF)
1. Review Owner-supplied data (program and budget)
2. Conceptual Site and Building Plans
3. Presentations
Brazos County Page 1
Architect Services Contract
Exhibit "A"
Scope of Services
B. Preliminary Design (First and Second Phases)
1. Architectural design/documentation
2. Structural design/documentation
3. Mechanical and electrical design/documentation
4. Material research/specifications
5. Agency consulting/review/approval
6. Statement of probable construction costs
C. Final Design (First and Second Phases)
1. Architectural design/documentation
2. Structural design/documentation
3. Mechanical and electrical design/documentation
4. Material research/specifications
5. Agency consulting/review/approval
6. Statement of probable construction costs
7. Presentations
D. RFP Preparations and Evaluation (First and Second Phases)
1. Bidding materials
2. Addenda as required
3. Proposal evaluation and recommendations
E. Construction (First and Second Phases)
1. Construction field observation
2. Submittal Review
3. Supplemental documents
4. Quotation requests/change orders
5. Project schedule monitoring
6. Construction cost accounting
7. Project close-out
Refer Exhibit "B" for current construction budget/phasing approved by the Courthouse
Renovation Committee. Upon approval of the Conceptual Design, basic services for the balance
of the contract will be based on the available budget or phase recommended and approved by the
Commissioners Court or appointed Committee. Patterson * Architects will prepare the final
construction drawings and specifications as required for bidding and construction.
It is Brazos County's intent that the Architect will be involved for the full duration of the design
development, preparation of construction, bidding documents and construction administration
phases of the project.
Brazos County Page 2
Architect Services Contract
Exhibit "B"
Payment Terms
ESTIMATED COST OF CONSTRUCTION
For the purpose of calculating the Architect's compensation prior to the receipt of Final
Construction Cost, the assumed cost of construction shall be based on the following estimated
cost of the construction. At the time a Final Construction Cost is determined for each portion of
the work, the Architect's fee shall be adjusted to the compensation stated in the paragraph below.
A. Conceptual Design for the entire Courthouse
Sitework $150,000.00
Renovation General/Office space 73,950 GSF @ $80.00/SF 5,916,000.00
Renovation Courtroom 51,700 GSF @ $110/SF 5,687,000.00
Contingency 4% 500.000.00
Total Estimated Construction Cost $12,253,000.00
B. Balance of Basic Services for Phase One
Sitework $150,000.00
Renovation General/Office space 28,125 GSF @ $80.00/SF 2,250,000.00
Contingency 41/2% 110,000.00
Total Estimated Construction Cost $2,510,000.00
C. Balance of Basic Services for Phase Two
Renovation General/Office space 5,970 GSF @ $80.00/SF 480,000.00
Renovation Courtroom 22,100 GSF @ $110/SF 2,430,000.00
Contingency 41/2% 130,000.00
Total Estimated Construction Cost $3,040,000.00
ARCHITECTURAL/ENGINEERING FEES
Basic Services -
For Architectural/Engineering Services as described in Exhibit "A", compensation shall be based
on ten percent (10%) of the construction cost to renovate the existing facility.
A/E Service % of Contract Amount
Conceptual Design 15% of 1,225,300.00 $183,800.00
Preliminary Design 20% of 555,000.00 111,000.00
Final Design 40% of 555,000.00 222,000.00
RFP Preparations & Evaluation 5% of 555,000.00 27,750.00
Construction 20% of 555.000.00 111.000.00
Subtotal Proposed A/E Fee 100% $655,550.00
LESS PRE-DESIGN SERVICES CONTRACT (27,500.00)
Total Architectural/Engineering Fees $628,050.00
Brazos County Page 1
Architect Services Contract
Exhibit "B"
Payment Terms
The County will reimburse the Architect for actual, non-salary expenses at the rate as scheduled
below. Unless amended by a duly authorized written change order, the total payment for all
invoices on this job, including both salary and non-salary expenses, shall not exceed the amount
agreed upon.
Reimbursable Expenses -
Reimbursable expenses shall be billed as follows:
Mileage: .48 cents per mile
Cost plus 10% for: postage, freight, film and development, long
distance telephone and printing
Large Format
Photocopies: $2.00 per sheet
Xerox copies: .15 cents per copy
Blueprints: $2.00 per sheet
Long-Distance
Communications: cost plus 10%
Other: Expenses not enumerated above shall be at cost plus
10%.
Reimbursable Expenses shall not exceed $6,000.00
The Cost of reproduction of Project Reports and Construction Documents will be billed
directly to the Owner.
Additional Services -
Any service that is not specifically designated in the description of the Design or Construction
Documents package shall be considered an additional service and shall be compensated at the
designated hourly rates.
Architectural Engineering
Principal: $125.00 Senior Engineer: $125.00
Project Architect: 95.00 Engineer in Training: 85.00
Intern Architect: 65.00 Senior Designers: 75.00
Drafter: 60.00 Drafter: 60.00
Administration: 45.00 Clerical: 45.00
The Architect will submit monthly invoices to the County, accompanied by an explanation of
charges, professional fees, services and expenses. Normal payment terms are no later than thirty
(30) calendar days after the Auditor's office receives the invoice. Payments will be made after
approval at a regular scheduled meeting of the Brazos County Commissioner's Court. The
Brazos County Commissioner's Court normally meets every Tuesday of each month.
Brazos County Page 2
Architect Services Contract
31